Category Archives: Contracts

Construction Termination Issues for the Architect and Engineer: Part 1– Introduction to the Series

Posted on by

Earlier this year, I was asked to talk to other construction lawyers on the topic of termination.  My first question was– whose termination are we talking about here– the architect / engineer?  The contractor?  Is someone wanting to “fire” the owner?  The answer, as it turns out, is — yes.  That is, yes, any and all of the above termination topics were on the table.

As you may have suspected, even the threat of a termination is bad, bad news.  It is the “nuclear option” for a construction project.  Everyone risks getting harmed.  As the design professional administering a contract, you run a risk of being dragged into litigation no matter what you do.  So, how should you proceed?  Carefully.

Elmer Fudd and dead Daffy Duck

As Elmer Fudd would say, be very, very careful!

To start, follow along in my new limited series on Termination Issues for Architects & Engineers (and all Design Professionals).  For the next few weeks, I’ll be posting about all sides of the termination topic, including:

Part 2:  How to handle construction administration when the contractor is getting fired

Part 3:  How to handle contract administration when the contractor is firing the owner

Part 4:  What to do when they want to fire you, the architect or engineer

Part 5:  What if You are the one that wants to quit?

and finally:

Part 6:  This is the End (Construction Contract Termination quick facts for the design professional)

Stay tuned for the next several weeks to learn all you ever wanted to know about termination, resignation, and the breaking of contracts.

In the meantime, if you have any burning termination-specific questions or comments, drop them in the comments below.  See you soon!

Photo By Leon Schlesinger Productions, produced for Warner Brothers. – YouTube screen capture; Public Domain,

Incorporation by Reference in your Design Services Contract– what does this mean, and are you at risk? (law note)

Posted on by

Has an Owner ever asked you to sign his contract before you started work on a new design project?  Rhetorical question– this happens all the time, right?  Especially in commercial work, developers or owners typically are not happy to simply agree to your Proposal for Services, but instead want you to sign *their* contract.

No to dogs drinking and smoking on skateboard

Make sure you know the risks you are taking on- or just say no!  (Sign in a cafe showing a smoking, drinking, skateboarding dog)

There are some risks with that you should be aware of — one of which is the seemingly arcane and legalistic language that reads something like this:

“The Developer’s contract with Owner is hereby incorporated by reference.”

What does this mean?  This language means that you have legal responsibilities that you may not even be aware of.  If the Developer agreed with the Owner to a certain a time frame (i.e., a  “time is of the essence” clause), or any particular performance standard (LEED certification, for example), then you also have agreed to these terms.  Did you know that?

So many times when I’m asked to review a contract for an architect, there is language incorporating a document that they never have even seen.  NEVER sign any such contract until you have gotten the document “incorporated by reference”, viewed it with your risk managers, insurance broker, and lawyer, and made the decision that you can live with those terms.

Clauses that are incorporated *are* legally enforceable.  Make sure you know what you are getting into.

Hat tip to Colleen Palmer at Beazley A/E whose Managing Risk video on this topic inspired today’s post.

What about you?  Have you asked for all documents you are agreeing to, before executing on a contract?  If not, start doing so today.

Photo (c) Melissa Brumback.  Creative Commons License

Expect the Unexpected (your design contracts in a post-COVID world)

Posted on by

Have you adapted your post-COVID practice to better plan for the “unexpected” ?  In particular, have you looked at–and revised– your professional services contracts to give yourself a little more breathing room for unaccounted issues that may arise?  If not, no time like the present.

Don’t like that saying?  How about ” a stitch in time saves nine?”  No?  Still nothing?  What about a picture of something so completely unexpected it shocks you– say, a fireman commuting home, in fire-fighting regalia, on a tricycle?  Okay, here you go…

Fireman-bikerNow that I have your attention– you should make it a practice to regularly review and update your professional services agreements, and you should consider issues such as:

  1.  Does your agreement provide for extra compensation if you have to spend more time or a longer period providing construction administration services for material delays or labor shortages?  If not, it should.
  2. Does your agreement have a well-written “act of God” provision– one that includes pandemic/epidemics as part of the “act of God” conditions in which a term may become void?  If not, add it now!
  3. Have you considered whether you want arbitration instead of litigation if a lawsuit does arise?  And if you want to arbitrate, does your contract give specifics, like how many arbitrators will decide the case?  These things can be added now with little effort, or you can pay your lawyer to negotiate them down the line.  Guess which is cheaper?

You *do* have a good, solid contract to begin with, correct?  If not, I’ve previously given examples of how to craft helpful scopes of services and how to add the protection of a well-crafted exclusion to your scope of services.   Check them out, and be ready for the next biker-fireman surprise in your future.

Photo (c) MelissaBrumbackCreative Commons License

Substitutions on a construction project — a Specification Writer responds

Posted on by

In response to the post about Substitute Materials on a construction project, Phil Kabza explains how his company, SpecGuy, handles tracking of all such materials on a project.specguy

Phil writes:

Excellent and important topic, about which there is much confusion among design professionals and contractors. We try to maintain definitions for:

  • Pre-bid requests for prior approval of proposed comparable products where products are named in the specifications
  • True pre-bid substitution requests that present an alternate type of product from that specified (ie., not “comparable” but perhaps suitable)
  • Post-award requests for approval of proposed comparable products “for convenience” of the contractor with or without credit to the owner
  • Post-award requests for approval of proposed comparable products “forcause” due to unavailability, failure to meet specified warranty, etc.
  • Submittal of non-complying products “to see if we can get away with it.”

Public agencies, owners, and design firms all have different approaches to each of the above, which requires the specifier to carefully define their terms in Division 00 Document “Procurement Substitution Procedures” and “Division 01 Section “Substitution Procedures,” as well as establishing consistency across the several hundred specification sections.

Thanks, Phil, for your boots on the ground perspective of how to consistently handle the specifications when handling substitute materials or products.

Your turn.  Thoughts or Phil or me?  Share below, or shoot me an email.

Substitute Materials — what are your duties? what are your risks? (law note)

Posted on by

In managing a project as the design professional, you are called upon to wear many hats.  One of those hats is that of material specifier and, at times, substitute material approver.  What are your duties in looking at substitute materials?many hard hats

As always, the legal answer is “it depends”.  In part, it will depend on your role on the project and what, specifically, the contract says.  However, at its most basic, you can be sued for accepting an out of spec substitute material.  This is so even if you believed the spec met requirements based on information that the contractor gave you.  So, tread carefully in this area.

Do not assume any information that the contractor presents to you– take the time to research for yourself, call the manufacturer, and otherwise ensure that the product will work.

If the substitute is okay but will mean the Owner will get something a little different, make sure the Owner knows that and has approved the change.  Needless to say, get this consent in writing, as it could be evidence one day.

While you may not ultimately be held responsible for approving a substitute that is inferior, you don’t need the headache of finding that out from a Court.  Save your time, and your stomach lining, and make sure it’s correct and documented on the front end.

Have you been called upon to approve questionable substitute materials?  How did you research whether they would work or not?  Share in the comments below or drop me an email.