Tag Archives: engineer

Root canals & Lawsuits: two things to avoid (Law Note)

Posted on by

man flossing

No one (with the exception of sadistic dentists)  likes root canals, and no one (except lawyers) likes lawsuits.  In the same way you can prevent (or limit) the need for root canals through proper flossing habits, you can limit the number of lawsuits you need to be involved in if you include everyone you should the first time around.  For those involved in filing construction liens, this means that when you perfect a lien by filing the lawsuit, be sure you include everyone you need to include.  A recent North Carolina Court of Appeals case demonstrates this principle in full living color.

In Lawyers Title Insurance Corp. v. Zogreo, LLC, __ N.C. App. __ (November 16, 2010), two contractors filed and perfected valid liens on a piece of property.  They did not include, in the lawsuits to perfect the liens, the banks which had given funds to the property owner after they first began work on the property.  The Court held that it was entirely proper not to include the banks (who held deeds of trust on the property to secure their loans); however, by the contractors’ failure to include them, they were forced to later litigate priority issues with the banks.  This is because “if a subsequent encumbrancer is not joined [in the underlying lien perfection lawsuit], he is not bound by the judgment in the action between the contractor and the owner.”

In other words, even though they filed proper liens, filed the lawsuits timely, and even won final judgment in those lawsuits, because they did not include the banks, the banks were free to start a new action, which they did in this case.  The banks also obtained an injunction to stop any judicial sale of the property until priorities could be established.

Moral of the story? It is better to include all subsequent encumbrancers (i.e., the banks) when perfecting a lien.  It’s not required, but it is better practice.  (And flossing your teeth isn’t required, either).   After all, who wants a root canal, or, in this case, to re-litigate your right to be paid money in yet another expensive lawsuit?  When it comes to root canals and lawsuits, fewer is better.

Sign up for email delivery of all blog posts directly to your email through the subscription box on the front page of the website.

——————-

Photo: Day One Hundred Fifty-One by Eric Mesa via Flickr/Creative Commons License

wind turbine

NC Green Contractors & Professionals Directory (Tue Tip)

Posted on by

wind turbineUpdate 3/9/2017: The NC Solar Center is now the NC Clean Energy Technology Center.  When last visited, the Professional Directory was no longer active.

Considering a Renewable Energy project?  Professional who specializes in green construction?  Either way, check out the North Carolina Green Professional Directory, published (with disclaimers) by the NC Solar Center.  The directory is searchable by professional type, by green technology, and by location, and professionals who qualify can apply to be added to the directory.

——————-

Photo from NC Solar Center

Active vs. Passive Negligence (Law note)

Posted on by

whole hog sign“As long as I was in, and in for good, I might as well go the whole hog.”

–Huck Finn, The Adventures of Huckleberry Finn by Mark Twain

————————-

If you work on a North Carolina construction project, you, too, are in “the whole hog” if you are negligent.  That is, if you are negligent at all, you are on the hook for the full lot.  As we’ve discussed, joint tort-feasors (that is, two negligent parties who are jointly & severally liable) are generally not entitled to indemnity from one another.

However, there are exceptions, and today we’re talking about one such exception– the passively negligent party.  

What is passive negligence?

Active negligence is an action which causes damage.  In contrast, passive negligence is negligence due to inaction, omission, or the failure to do something that you are legally obligated to do.   The actively negligent party is primary responsible for paying any damages, and the passively negligent party is only secondarily liable.

For example, if a subcontractor is actively negligent in constructing the framing for a building, and the general contractor failed to notice the defect, the subcontractor is actively negligent and the general contractor is passively negligent. 

Indemnity of the passively negligent party

Where the active negligence of one tort-feasor and the passive negligence of another combine to proximately cause injury to a third party, the passively negligent tort-feasor who is compelled to pay damages to the injured party is entitled to indemnity from the actively negligent tort-feasor.  This is called common-law indemnity, as opposed to contractual indemnity, which we discussed in an earlier blog post. 

In our example above, the subcontractor, as the actively negligent party, is the party ultimately responsible for the poor framing and the resulting damages.  If the general contractor is sued by the owner, he can in turn sue the subcontractor for the damages which were caused by the sub.

Questions about active versus passive negligence?  Drop me a line in the comments below.

—————————-

Photo “Whole Hog Heaven BBQ” by Bill.Roehl via Flickr/Creative Commons license.

Contributory Negligence on the construction project (law note)

Posted on by

scale of justiceI’m sometimes asked if the percentage of “fault” is something that a client can rely on to reduce the amount of money they may owe on construction project gone bad.  The short answer:  no.   As I mentioned in my post on joint & several liability, if you are even 1% liable for the damages on a project, you can be hit with 100% of the damages. 

 This is not true in many other jurisdictions, where proportional fault (called comparative negligence) is often allowed.  In those states, if you are found 20% liable, you only have to pay 20% of the damages. Not so in North Carolina.  Here, unless you are entirely passively negligent (a concept we’ll discuss next week), you may be on the hook for the full amount.

That’s not fair!

Perhaps.  But, that’s life on a North Carolina construction project.  One concept that helps to reduce the unfairness factor is the concept of contributory negligence.  In North Carolina (but few other states), if a party is negligent at all (even 1%), they cannot recover from another negligent party.  

For example:  the owner of a project sues its general contractor on a project for a late project delivery which costs the owner money.  While almost all of the delay was the contractor’s fault, the owner also caused delay by failing to deliver owner-furnished equipment in time to meet the critical path of the project.  The owner’s own failure means that the owner itself is contributorily negligent and, under North Carolina law, the owner cannot recover the rest of its damages from the contractor.

But wait! There’s more.

Before you get too excited about contributory negligence, you need to understand the concept of  jury nullification.  When contributory negligence is explained to a jury, the jury may sometimes decide not to find fault where they might otherwise apportion fault, to avoid what they perceive as an unjust result. 

In the above example, the jury might decide the owner’s failure was not really contributing to the delay after all, and therefore award the owner damages.  This is called jury nullification, and it can take the sting out of contributory negligence.

Change to NC’s Contributory Negligence law?

The concept of contributory negligence (and its complete bar to any recovery) is one which many would like to change.  There has been legislation in the NC General Assembly in recent years to abolish contributory negligence in favor of a comparative-fault  negligence, as is common in most states.  So far, this has not happened.  As they say, however, the jury is still out on whether such a change will occur.  

Do you have an opinion on contributory negligence vs. comparative negligence? Think NC’s law should change to one based on percentage of fault?  Share in the comments below.

———————

Photo “Scale—Image”  by Matthias Kulka/Corbis via Picasa/Creative Commons License. 



Liquidated Damages: what, when, & why

Posted on by

water dropWhat are Liquidated Damages?

Liquidated Damages are a sum which a party to a contract agrees to pay or a deposit he agrees to forfeit, if he breaks some promise.  In the construction realm, liquidated damages (or “LDs”) usually involve money damages for time delays on a construction project.    Typically, a contract will state that time is “of the essence” and that for every day past the scheduled completion date (as modified by change orders & directives) a set amount is due from the contractor to the owner.

When can you get liquidated damages? (or, when must you pay liquidated damages?)

Liquidated damages must be specified in the contract up front.  They should reflect the reasonable estimate of likely damages that will be incurred if the contractor fails to complete the project timely.

To be enforceable, the amount must have been arrived at by a good-faith effort to estimate in advance the actual damage that would likely ensue from the breach, and they cannot be deemed “penalties.”  Eastern Carolina Internal Medicine, P.A. v. Faidas,  149 N.C.App. 940,  564 S.E.2d 53 (2002).

Why?

The purpose of liquidated damages is to reasonably compensate the non-breaching party (typically, the owner for construction delays) which it will likely incur as a result of the breach (e.g., the extended completion date results in lost rent and increase finance charges).  Without the liquidated damages provision, the parties would be forced to argue about each alleged cost the owner incurred because of the delay.  With liquidated damages, the amount is known ahead of time which should (theoretically) lead to fewer arguments later.

When doesn’t the provision work?

Two words—concurrent delay.  If the owner is delaying the project (through, for example, failure to deliver/install owner-provided equipment), but the contractor is also behind on completion, the two delays may run at the same time—hence “concurrent delay”.  In such a situation it becomes difficult if not altogether impossible to separate delays and delay damages.  Of course, if the entire delay is owner-related, no liquidated damages can be assessed.

Take-away message

Liquidated damage provisions, if carefully and properly drafted, are enforced in North Carolina.  You should know your schedule requirements prior to signing on the dotted line and, if necessary, accelerate your work to complete on time.  If you are the owner, however, you also have responsibilities not to interfere with the schedule if you hope to have a chance at recovering liquidated damages from a contractor who delivers a project late.

Questions?  Comments?  Experience with the joys (and sorrows) of LDs?  Share in the comments below.

 __________________________

Photo “Water drop bouncing off the water surface” by konradc via Picasa/Creative Commons License.